TERMS AND CONDITIONS
Cube Construction Inc.
California
Last Updated: 08/20/2024
These Terms and Conditions (“Terms”) govern the use of the Cube Construction Inc. website and all construction, remodeling, and contracting services provided by Cube Construction Inc. (“Company,” “we,” “our,” or “us”). By accessing this website or engaging our services, you agree to these Terms.
⸻
1. California Licensed Contractor
Cube Construction Inc. is a licensed General Contractor in the State of California (CSLB License #1127504). All construction services are performed in accordance with the California Business and Professions Code, California Building Standards Code, and all applicable local, state, and federal regulations.
⸻
2. Informational Purpose of Website
All information provided on this website is for general informational purposes only and does not constitute a binding offer, contract, or guarantee. Actual project terms, pricing, schedules, and scope of work are defined solely in a written agreement, estimate, or contract executed by both parties.
⸻
3. Scope of Services
Services may include general contracting, remodeling, renovation, remediation, and construction project management. The specific scope of work, materials, timelines, and pricing will be outlined in the applicable written agreement. Any services not expressly included in such agreement are excluded.
⸻
4. Estimates and Pricing
All estimates are approximate and subject to change due to site conditions, design modifications, material availability, regulatory requirements, or other factors beyond the Company’s control. Final pricing is determined by the executed contract and approved change orders.
⸻
5. Project Scheduling and Delays
Project schedules are estimates only. Cube Construction Inc. is not responsible for delays caused by circumstances beyond reasonable control, including but not limited to:
• Permit and inspection delays
• Changes required by governmental authorities
• Weather conditions
• Material or labor shortages
• Client-requested changes
• Acts of God or other force majeure events
Schedule adjustments due to such delays do not constitute breach of contract.
⸻
6. Payments and Right to Suspend Work
Payment terms, deposits, progress payments, and retention are governed exclusively by the executed contract or approved estimate. Cube Construction Inc. reserves the right, to the extent permitted by California law, to suspend work for non-payment without liability for resulting delays or damages.
⸻
7. Change Orders
All changes to the scope of work, materials, design, or schedule must be documented in a written Change Order signed by both the Client and Cube Construction Inc. Verbal or informal agreements are not binding under California law.
⸻
8. Warranty
Cube Construction Inc. provides warranties as required by California law and as specified in the applicable contract. Unless otherwise stated in writing, warranties apply only to workmanship and exclude:
• Normal wear and tear
• Improper use, abuse, or lack of maintenance
• Work or materials supplied by others
• Manufacturer defects covered by separate warranties
Statutory warranties under California law remain unaffected.
⸻
9. Insurance and Workers’ Compensation
Cube Construction Inc. maintains General Liability Insurance and Workers’ Compensation Insurance in compliance with California law. Proof of insurance is available upon request prior to commencement of work.
⸻
10. Limitation of Liability
To the fullest extent permitted under California law, Cube Construction Inc. shall not be liable for any indirect, incidental, special, or consequential damages, including loss of use, loss of profits, or project delays.
The Company’s total liability shall not exceed the total amount paid by the Client for the services giving rise to the claim.
⸻
11. Force Majeure
Cube Construction Inc. > Сергей: shall not be responsible for delays or failure to perform caused by events beyond reasonable control, including but not limited to natural disasters, fires, floods, acts of government, labor disputes, pandemics, supply chain disruptions, or other unforeseeable events.
⸻
12. Mechanic’s Lien Rights (California Notice)
Pursuant to California law, Cube Construction Inc. reserves the right to file a mechanic’s lien for unpaid labor or materials provided. Clients are encouraged to familiarize themselves with their rights and obligations under California lien laws.
⸻
13. Intellectual Property
All website content, including text, images, logos, designs, and branding, is the property of Cube Construction Inc. and may not be copied, reproduced, or used without prior written consent.
⸻
14. Website Use
Users agree not to misuse this website, attempt unauthorized access, upload harmful content, or interfere with website functionality. Cube Construction Inc. may restrict or terminate access for violations of these Terms.
⸻
15. Dispute Resolution and Governing Law
These Terms are governed by the laws of the State of California. Any dispute arising out of or relating to these Terms or services provided shall be subject to the exclusive jurisdiction of the courts located in San Mateo County, California.
Where required by law, the parties agree to attempt non-binding mediation prior to litigation.
⸻
16. Amendments
Cube Construction Inc. reserves the right to modify these Terms at any time. Updates will be posted on this page, and continued use of the website or services constitutes acceptance of the revised Terms.
⸻
17. Contact Information
For questions regarding these Terms and Conditions, please contact Cube Construction Inc. using the contact details provided on this website.
SMS Terms & Conditions
1- SMS Consent Communication:
Information (Phone Numbers) obtained as part of the SMS consent process will not be shared with third parties for marketing purposes.
2- Types of SMS Communications:
If consent has been given to receive text messages from Company’s name, messages may be received related to the following:
Appointment reminders
Follow-up messages
Example: Thank you for reaching out to company’s name. We’ve received your inquiry and are working on a solution. Our team will update you within [timeframe].
For any further questions, feel free to reply or contact us at +1 408-677-2424.
3- Message Frequency:
Message frequency may vary depending on the type of communication. For example, up to 10 SMS messages per week may be received related to appointments/billing, etc..
4- Potential Fees for SMS Messaging:
Standard message and data rates may apply, depending on the carrier’s pricing plan. These fees may vary if the message is sent domestically or internationally.
5- Opt-In Method:
Opt-in to receive SMS messages from Company’s name can be done in the following ways:
They fill out a form
6- Opt-Out Method:
Opting out of receiving SMS messages can be done at any time by replying “STOP” to any SMS message received. Alternatively, direct contact can be made to request removal from the messaging list.
7- Help:
For any issues, reply with the keyword HELP. Alternatively, help can be obtained directly from us at (insert the link or phone number)
Additional Options:
If SMS messages are not desired, the SMS consent box on forms can be left unchecked.
8- Standard Messaging Disclosures:
Message and data rates may apply.
Opt out at any time by texting “STOP.”
For assistance, text “HELP” or visit our Privacy Policy and Terms and Conditions pages.
Message frequency may vary
